Skyline Engineering Contracts ... vs Union Of India & Ors. on 19 February, 2024
Author: Vibhu Bakhru
Bench: Vibhu Bakhru
IN THE HIGH COURT OF DELHI ... delivered on: 19.02.2024
+ W.P.(C) 4023/2020
M/S SKYLINE ENGINEERING CONTRACTS
(INDIA) PVT LTD ..... Petitioner
versus
UNION OF INDIA & ORS. ..... Respondents
Advocates
faculty in the College of
Engineering, Cochin University College of Engineering, Kuttanadu
and Kunjali Marakkar School of Marine Engineering, conducted by
the University, by which ... ELECTRICAL ENGINEERING AT THE SCHOOL OF
ENGINEERING FOR A PERIOD OF THREE MONTHS
W.E.F. 08.02.2024 OR TILL FRESH
CONTRACT/REGULAR APPOINTMENT IS MADE
faculty in the College of
Engineering, Cochin University College of Engineering, Kuttanadu
and Kunjali Marakkar School of Marine Engineering, conducted by
the University, by which ... ELECTRICAL ENGINEERING AT THE SCHOOL OF
ENGINEERING FOR A PERIOD OF THREE MONTHS
W.E.F. 08.02.2024 OR TILL FRESH
CONTRACT/REGULAR APPOINTMENT IS MADE
engineering, procurement, manufacturing, supply, inspection,
testing and commissioning of the PV Plant.
17. Respondent No.2 (the Engineering Company) was obliged under
the contract ... Juwi India:- (i) Equipment and Material
Supply Agreement; and (ii) Engineering,
Installation and Commissioning Contract and
the parties to Sale and Purchase Agreement
between Rishabh
engineering, procurement, manufacturing, supply, inspection,
testing and commissioning of the PV Plant.
17. Respondent No.2 (the Engineering Company) was obliged under
the contract ... Juwi India:- (i) Equipment and Material
Supply Agreement; and (ii) Engineering,
Installation and Commissioning Contract and
the parties to Sale and Purchase Agreement
between Rishabh
contractor repudiates the contract
exercising his right to do so under Section 55 of
the Contract Act,
(ii) the employer gives an extension of time ... referring to the
American jurisprudence in Hudson's Building and Engineering Contracts and
literature / Indian jurisprudence in Chitty on Contracts and with reference
Territory of Pondicherry. The invitation was, essentially, to enter
into a rate contract and the tenderer was required to offer rates expressed
in the form ... business of steel
fabrication and executing civil and electrical engineering contracts.
9. The bid documents included the SIT, which inter alia, stated the
procedure
have only contended that as per the terms of the contract, no amount
under these heads was payable as the petitioner's decision ... read as
under:
"14. In Hudson's Building and Engineering Contracts
(11th Edn., pp. 1098-99) there is reference to "no-
damage
Rishabh with Juwi India:- (i) Equipment and Material
Supply Contract (01.02.2012); and (ii) Engineering,
Installation and Commissioning Contract (01.02.2012)
and the Rishabh's Sale ... following
decisions:
• Elite Engineering (supra)
• NBCC (India) Limited (supra)
49. In Elite Engineering (supra), NHAI awarded a contract to M/s. T.K.
Toll Road
criticism:
"(a) Hudson Formula : In Hudson's Building and Engineering
Contracts, Hudson formula is stated in the following terms:
"Contract head office
