Income Tax Appellate Tribunal - Mumbai
Ito Wd 4(4), Thane vs Hari Om Builders And Developers, Mumbai on 5 February, 2018
आयकर अपील य अ धकरण, मुंबई यायपीठ,'ए',मुंबई।
IN THE INCOME TAX APPELLATE TRIBUNAL MUMBAI BENCHES "A", MUMBAI ी जो ग दर संह, या यक सद य एवं ी जी. मंजूनाथ, लेखा सद य, के सम Before Shri JOGINDER SINGH, Judicial Member, and Shri G. MANJUNATHA, Accountant Member ITA NO.3306/Mum/2016 Assessment Year: 2011 - 2012 Income Tax Officer Ward Hari Om Builders & Developers, 4(4), Thane (W) बनाम/ 1 Manohar Nagar, Opp Shiv Shakti Complex, Valiv, Vasai (E) Vs. Mumbai 401 208 (राज व /Revenue) ( नधा!रती /Assessee) P.A. No. ABDFS3536P CO No.261/Mum/2017(Arising out of ITA NO.3306/Mum/2016 AY: 2011 - 2012 Hari Om Builders & Income Tax Officer Ward Developers, Mumbai 401 208 बनाम/ 4(4),Thane (W) (Cross-Objector) (Respondent) Vs. राज व क+ ओर से / Revenue by Shri Rajesh Kumar Yadav DR नधा!रती क+ ओर से / Assessee by Shri Subodh Ratnaparkhi ु वाई क% तार&ख / Date of Hearing :
सन 05/02/2018
घोषणा क% तार&ख/Date of Pronouncement 05/02/2018
आदे श / O R D E R
Per Joginder Singh (Judicial Member) The Revenue is aggrieved by the impugned order dated 2nd February, 2016 of the learned first appellate authority 2 allowing deduction u/s. 80IB(10) of the Income Tax Act, 1961 (hereinafter the Act), amounting to Rs 2,80,10,538/- relying upon the decision from Hon'ble Gujarat High Court in the case of Tarnetar Corporation (2012) 26 taxman.com 180 (Guj). The assessee has also filed cross-objection with respect to the same deduction u/s. 80IB(10), originally allowed in the assessment framed u/s. 143(3) of the Act by holding that the same is a mistake apparent from record by passing an order u/s. 154 of the Act, which is not maintainable under the Act.
2. First we shall take up the appeal of the Revenue. The only ground raised by the Revenue is with respect to allowability of deduction u/s. 80IB(10) of the Act. The facts in brief are that the assessee declared 'nil' income in its return filed on 29.09.2011, after claiming deduction u/s. 80IB(10) of the Act amounting to Rs 2,80,10,538/- on the project of building 1, 2 and 3. The assessment u/s. 143(3) was completed on 08.08.2003 allowing the claimed deduction. Originally, CIDCO was the legal authority for Vashi area where the project of the assessee is situated and later on the said area came within the jurisdiction of Vasai 3 Virar Municipal Corporation. A show cause notice u/s. 154, dated 10.04.2014, was issued to the assessee. As per the Revenue the assessee could not submit the completion certificate even after affording a reasonable time thus, the claimed deduction u/s. 80IB(10) was allowed. The assessee was aggrieved by the rectification order passed by the learned Assessing Officer therefore, appeal was preferred before the learned CIT(A) where the addition made by the Assessing Officer was deleted. The learned CIT(A) deleted the addition on the plea that the buildings were completed before 31st March 2011, therefore, the conditions of section 80IB(10) stood fulfilled. The learned CIT(A) relied upon the decision in the case of CIT vs. Hindustan Samuha Awas Limited. In that case it was held that where the assessee undertook a housing project and completed the same within time and moved the application for completion certificate within time but the same was issued after a delay, such delay could not be attributed to the assessee and the assessee would be entitled for deduction u/s. 80IB(10) of the Act. The case of the Revenue is that since the completion certificate was not issued within time by the local authority, therefore, the required conditions prescribed u/s. 80IB(10) 4 of the Act were not fulfilled by the assessee. There is no dispute to the fact that the project was completed as per the prescribed conditions within the stipulated period and the application for grant of completion certificate was applied within time, therefore, in principle, we are in agreement with the finding of the learned CIT(A) that if there is any lapse on the part of Municipal Authorities in issuing the completion certificate, the assessee cannot be penalized. It is also noted that originally the assessment was framed u/s. 143(3) of the Act on 08.08.2003 that too on examination/verification of the return, filed by the assessee. In the original assessment, there is a finding that the assessee has complied with all the conditions imposed by the provisions of the Act. The rectification u/s 154, of the Act carried out by the assessee as on the premise that the project of the assessee was without occupation certificate therefore, the claimed deduction originally allowed u/s. 143(3) on 08.08.2003 was wrongly allowed. It is further noted that CIDCO was the original local authority for Vashi (East) and thereafter the jurisdiction was transferred to Municipal Corporation (VVMC). Due to change in the authority the occupancy certificate got delayed and the certificate for building no.1 5 was granted by CIDCO on 27.03.2008 but with respect to building No. 2 & 3 which were completed on 22.03.3011 got delayed due to change of approving authority. We have perused the record along with application dated 22.03.2011 for grant of occupancy certificate with respect to building no. 2 & 3, sample copies of electricity bills of flats in building no 2 & 3, evidencing installation of electricity meters and supply of electricity, occupancy certificate of building nos. 2 & 3 issued by VVMC on 31.05.2014 (all documents are attached in the paper-book of the assessee), thus, the decision from Hon'ble jurisdictional High Court in Hindustan Samuh Awas Limited (62 taxman.com 175)(Bom), CIT vs. Tarnetar Corporation (26 taxman.com 180) (Guj), Income Tax Officer vs. Saket Corporation (62 taxman.com
38) (Guj), M/s. D K Construction vs. Income Tax Officer (IA No. 243/Indore/2010 dated 6.12.2010) we find no infirmity in the order of the learned CIT(A).
3. So far as order u/s. 154 of the Act, withdrawing the deduction originally allowed u/s. 80IB(10) is concerned, we find that the learned CIT(A) has rightly observed that it was not a mistake apparent from record as the original order 6 was passed u/s. 143(3) of the Act. The learned CIT(A) has already mentioned various decisions with respect to the issue and withdrawal of claim u/s. 80IB(10) of the Act was not a mistake apparent from record. Even otherwise, on merits, the claim of the assessee is quite justified. We affirm the stand of the learned CIT(A) with respect to claim u/s. 80IB(10) in which we find no infirmity.
4. So far as the cross-objection no.261/Mum/2017 is concerned, since we have dismissed the appeal of the Revenue on the issue of claimed deduction u/s. 80IB(10), in favour of the assessee, therefore, the cross-objection of the assessee has remained for academic interest only, consequently dismissed as infructuous.
Finally, the appeal of the Revenue and Cross-objection of the assessee are dismissed.
This Order was pronounced in the open court in the presence of learned representatives from both sides at the conclusion of the hearing on 5th February, 2018.
Sd/- Sd/-
(G. Manjunatha) (Joginder Singh)
लेखा सद3य / ACCOUNTANT MEMBER या4यक सद3य / JUDICIAL MEMBER
मब
ुं ई Mumbai; +दनांक Dated : 05/02/2018 SA 7 आदे श क+ 54त7ल8प अ9े8षत/Copy of the Order forwarded to :
1. अपीलाथ/ / The Appellant
2. 01यथ/ / The Respondent.
3. आयकर आय3 ु त,(अपील) / The CIT, Mumbai.
4. आयकर आय3 ु त / CIT(A)- , Mumbai
5. 5वभागीय 0 त न ध, आयकर अपील&य अ धकरण, मब ंु ई / DR, ITAT, Mumbai
6. गाड फाईल / Guard file.
आदे शानस ु ार/ BY ORDER, उप/सहायक पंजीकार (Dy./Asstt. Registrar) आयकर अपील य अ धकरण, मब ुं ई / ITAT, Mumbai