Himachal Pradesh High Court
Hindustan Construction Company Ltd vs Himachal Pradesh Power Corporation Ltd on 8 October, 2020
Author: Sandeep Sharma
Bench: Sandeep Sharma
IN THE HIGH COURT OF HIMACHAL PRADESH, SHIMLA
Arb. Case No. 49 of 2018
Date of Decision: 8.10.2020
.
______________________________ _______________________________________
[
Hindustan Construction Company Ltd. .........Petitioner
Versus
Himachal Pradesh Power Corporation Ltd. .......Respondent.
Coram
Hon'ble Mr. Justice Sandeep Sharma, Judge.
Whether approved for reporting1?
For the petitioner: Mr. Janesh Gupta, Advocate.
For the respondent: Mr. J.S. Bhogal, Senior Advocate, with Mr. Suneet
Goel, Advocate.
___________________________________________________________________________
Sandeep Sharma, J. (Oral)
Being aggrieved and dissatisfied with issuance of letter dated 22.2.2018 (Annexure P-3), whereby petitioner has been directed to pay the liquidated damages to the tune of Rs. 29,69,06,957.60/-, as determined by the respondent-Himachal Pradesh Power Corporation Ltd., on the tendered amount of work shown in the agreement within a period of one month, failing which such amount shall be adjusted or set off against any sum payable to it under this or any other contract with HPPCL, petitioner has approached this Court in the instant proceedings filed under Section 9 of the Arbitration and Conciliation Act, seeking appropriate direction restraining the respondents Whether reporters of the Local papers are allowed to see the judgment?
::: Downloaded on - 08/10/2020 20:19:28 :::HCHP -2-from encashing/enforcing the bank guarantees furnished in favour of the respondents.
.
2. Having heard learned counsel for the parties and perused material available on record, this Court finds that there is no dispute inter-se parties that arbitral Tribunal stands constituted to adjudicate the dispute inter-
se parties arising out of the contract agreement No. Kashang/Civil-I for the work "Construction of Civil works comprising River diversion, Intake Structure, Conveyance Channel, De-silting basins, Power Channel, Head race Tunnel, Underground Balancing reservoir, Pressure Shaft, Valve Chamber, Adit to Valve Chamber/Balancing Reservoir, Civil works of underground Power House/Transformer Hall including various adits in power House complex and tail race tunnel complete in all respects of Kashang HEP (65MW x 3 units) in Distt. Kinnaur, Himachal Pradesh, India-Intimation regarding levy of Liquidity Damages under Sub Clause 8.7 of GCC read with PCC of said Contract Agreement" and petitioner is aggrieved of communication dated 22.2.2018, which has been issued with respect to aforesaid contract. Since dispute with regard to aforesaid contract is pertaining to Kashang project and same is pending adjudication before the Arbitral Tribunal, present petition is not maintainable; rather petitioner is required to approach the arbitral Tribunal seeking injunction against the aforesaid letter, if so advised.
3. Consequently, in view of the above, present petition is disposed of reserving liberty to the petitioner to approach the Arbitral Tribunal for the reliefs as have been prayed for in the instant petition. Needless to say, Arbitral ::: Downloaded on - 08/10/2020 20:19:28 :::HCHP -3- Tribunal shall consider the prayer of the petitioner in accordance with law.
Pending application(s), if any, also stand disposed of accordingly.
Copy dasti.
.
8th October, 2018 (Sandeep Sharma),
manjit Judge
r to
::: Downloaded on - 08/10/2020 20:19:28 :::HCHP