Document Fragment View

Matching Fragments

13. Claim No.7 was made by the claimant for Rs.12,78,504.66. This claim had been made towards anticipated profits on the left out/unexecuted portion of the work at the rate of 10% of the balance work. The basis for this claim made by the claimant was that the claimant was not able to complete the work due to the defaults of the petitioner department and circumstances beyond their control, without any default on their own part. As per the award, the amount of claim covers infructuous expenditure also incurred for the execution of the entire work including mobilization of tools, plant and machinery and construction of stores, site office, labour camp, steel yard and cement stores etc. and idle maintenance of site staff and site telephone. The balance estimate of work was worked out at Rs.1,02,28,037.30. Since the award of the tender was 25% above the estimate, the said figure was revised to Rs.1,27,85,046.60.

"43. The cement will be supplied by the department at the rate of Rs.137/- each bag for PPC/OPC inclusive of the cost of bags. The department will be free to supply cement from its own stores or from any store of other department in Delhi or from the railway sidings and the contractor shall make his own arrangement for carting the same to the site of work and store the same properly. No payment on this account shall be made. The recovery of cement shall be made from the running bills of the contractor at the above specified rate. The tentative quantity of cement is 927.40 MT".

"30. Any delay in supply of materials stipulated to be issued by the department will be no excuse for enhancing or affecting the rates once tendered. The contractor should in such cases apply in time for extension of time and such applications will be disposed off on their merits".
"43. The cement will be supplied by the department at the rate of Rs.137/- each bag for PPC/OPC inclusive of the cost of bags. The department will be free to supply cement from its own stores or from any store of other department in Delhi or from the railway sidings and the contractor shall make his own arrangement for carting the same to the site of work and store the same properly. No payment on this account shall be made. The recovery of cement shall be made from the running bills of the contractor at the above specified rate. The tentative quantity of cement is 927.40 MT".