held that the terms and conditions
for contracts of generating company for equipment suppliers
and EPC contracts need not be regulated by the State
Commission ... clearly demonstrated by
specifications adopted by LITL under EPC contract dated
24.12.2006 and awarded EPC contract for 2x600 MW.
(L) CPRI report was introduced
which were disallowed by Commission, are directly traceable
to the EPC Contract with NECL and the chain of correspondence arising
therefrom. It was submitted that ... basis of audited accounts, without
relying on or producing the EPC Contract or related correspondence.
10. On merits, PSPCL submitted that the documents are narrative
contract in terms of
Clause 25.4 of the General Conditions of contract. Further, as
per Clause 2.1 read with Clause 2.3 of the EPC Contract ... services under the EPC Contract were supplied within the
Scheduled Completion/Delivery date as per Clause 3.0 of the
EPC Contract. The benefit of unit
supply of 260 MW from the Station.
f) The Appellant awarded EPC Contract to SEPCO (Chinese
Company) on 28.8.2008. Notice to Proceed (NTP) was issued ... under the main Project Area. This delay
was concurrent with the EPC contract related delays;
iii. Delay in the acquisition of land required for railway
entrust these works also to the
EPC contractor by way of two Miscellaneous contracts in addition to
EPC contract of Rs. 3526.64 Crores. The Central ... they could not have entered into an EPC contract for 2x600 MW
plant. The EPC contract had to be as per the capacity agreed
practice is that the EPC
contracts are lumpsum fixed price contract and
subsequent to placing of orders for EPC contracts, the
same is further divided ... supply and local erection contracts. The total amount
of the 3 contracts is the same as agreed in the EPC
contract. The TNEB has also
Bses Rajdhani Power Ltd vs Delhi Electricity Regulatory ... on 6 October, 2009
Before the Appellate
M/S. Everest Power Pvt Ltd vs Punjab Electricity Regulatory ... on 12 November, 2014
APPEAL
Station.
g) The Respondent No. 1 awarded Engineering, Procurement and
Construction (EPC) Contract to SEPCO (Chinese Company) on
28.8.2008. Notice to Proceed (NTP) was issued ... line with the EPC Contract is not
prudent on the ground that the Time Lines of the EPC Contract are
beyond the Time Line agreed
that such expenditure
mainly pertains to deferred liabilities against EPC contracts and non-
EPC contracts.
16.3 That the Impugned Order contains no justification for including ... contract signed with BHEL for setting up of Mejia TPS Unit-4. It is an
admitted position that the EPC contract provided that
