fairly conceded by the learned counsel for all parties that the core
issue to be addressed, and on which the result of this challenge would ... Mumbai could not be increased due to
space constraints and environmental issues, the proponent R-Infra being
called upon to submit
process of being retired and closed in view of the serious
environmental issues affecting the said generating units. The Environmental
Authorities have been serving notices
project of the Respondent no.2 had got delayed due to
the environmental clearance and also on account of non grant of
permission to expand ... Page 33 of 57
Appeal no. 6 of 2015
due to environmental issue decided to restrict size of the project
limited to present capacity
Judgment in Appeal No. 173/09
14. The next issue is increased Heat Rate. According to the
Appellant, the State Commission did not consider ... Kcal/unit. According to the Appellant due
to the environmental issues the unit being located within the
metropolitan area, this unit had to shift
Clearance
which according to petitioner is a time consuming process.
This issue of Environmental Impact Assessment Clearance was
neither brought out in the petition ... categorically stated that the Appellant had not brought out the issue
of Environmental Impact Assessment Clearance in its earlier Petition
No. 60 of 2012 submitted
Solid
Waste, Wheat/Paddy Straw and even Polythene, thereby addressing
the environmental issues arising from their burning/non-disposal, which
is otherwise creating health hazard
work.
o The reasons for delay stated by MEGPTCL include RoW issues, delayed
Forest clearances, land availability for Sub-stations, non-availability of
shut downs ... known that power transmission and other infrastructure projects
are generally face issues relating environmental / forest clearances, land
acquisition and RoW. MEGPTCL is part
observe any issue involving environmental clearance in
this matter. As we observe, it is simply an administrative
issue involving the concerned agencies in the State
entitled to proceed on the
basis that Environmental Clearance shall be absolute and
unconditional. So also the Environmental Clearance dated
03.10.2008 to the Appellant ... under the RFP or Guidelines to acquire
Environmental Clearance is not relevant in the present case. The
issue in the present case is not whose
Talwandi Sabo Power Limited vs Punjab State Power Corporation Ltd & ... on 7 April, 2016
