approved by
the State Commission. We find that the schemes are for
conversion of LT overhead conductor (bare conductor) into AB
cables, electrification of some ... network,
replacement work of LT Distribution Box and service lines,
conversion of overhead lines crossing the main road to
underground cable for the Commonwealth Games
Inspector for charging
of the line and for safety and security issues connected with the
generating station and line connectivity, installation of metering
arrangement, synchronization ... delay in the DC issuing orders for land conversion, delay in
according approval for evacuation line etc., as a result of which it
was unable
Appeal no. 01 of 2013
and 19 of 2013
conductoring & conversion of lines which were
classified as revenue expenses. Further, out of the total
entity shall not be allowed to apply to the
Board for conversion of its dedicated pipeline into a natural gas
pipeline for a period ... Board may decide to authorize the
entity for such conversion in line with the procedure under clause
(d) of sub-regulation (1) and the moratorium
nature of the line to be
laid down namely 220 KV line instead of 400 KV DC line to
Varsana sub station. The delay ... terms and conditions for allowing the above
namely conversion of the dedicated line from 400 KV DC line to
220 KV line from Bhadreshwar
clear that the Respondent No. 2 is
also in line with the view that the conversion of Kayamkalam plant
from Naphtha fuel to Multi fuel ... hence kindly proceed for
the conversion on the above lines."
5.12 It was always made clear that the conversion of technology is
subject
State
Commission wherein they have allowed the cost incurred towards
conversion to 132 KV lines and its associated works for
capitalization and as a result ... such line was the evacuation line for 8 MW power plant
and also that there was no other use of the said line
Page 9
commissioning, and civil works and Contract for Transmission Line
Works and concluded the tender on 20.11.2017.
22. On 18.12.2017, the Appellant acquired ... level byerecting 110 KV DC line from
the plant after completion of following works:
(a) Conversion of 110 kV Theni - Sembatti Feeder
implementation of the project. These include
principally, the following:
(a) Approval for conversion of the land from agricultural purpose to be used
for setting ... Inspector for charging of the line
and for safety and security issues connected with the generating station
and line connectivity, installation of metering arrangement,
synchronization
Inspector for charging
of the line and for safety and security issues connected with the
generating station and line connectivity, installation of metering
arrangement, synchronization ... transmission line Appeal
2 Application for evacuation of 30.06.2015 20.10.2015 3 and half Para 7 (O)
power months Of Appeal
3 Application for conversion
