possession was caused on account of stay order passed by the NGT regarding ground water extraction for construction purposes.
4. The first plea advanced ... contract.
7. As far as delay on account of the NGT orders is concerned, the plea was considered by this Commission in CC/40/2017
another matter Amit Kumar & Ors. Vs. Union of India , the NGT had passed an interim order stopping the construction work within a radius ... possession was caused on account of stay order passed by the NGT regarding ground water extraction for construction purposes.
7. As far as delay
copy of the order dated 11.01.2013 passed by the NGT), Exhibit RW-1/6 (copy of the order dated 14.08.2013 passed by the NGT), Exhibit ... copy of the order dated 17.09.2013 passed by the NGT), Exhibit RW-1/8 (copy of the order dated 28.10.2013 passed by the NGT), Exhibit
economic slow-down. It has been stated that the National Green Tribunal (NGT) vide its order dated 11.01.2013 had restrained the builders to use ground ... water for construction activity and subsequently on 14.08.2013 the NGT ordered stoppage of construction within 10 km radius of the Okhla Bird Sanctuary
question, and (c) imposition of restrictions by the National Green Tribunal (NGT) over use of ground water and sand for construction purposes in the National ... record any evidence to establish how these, including the ban by the NGT impacted the project specifically. The argument that the delay
question, and (c) imposition of restrictions by the National Green Tribunal (NGT) over use of ground water and sand for construction purposes in the National ... record any evidence to establish how these, including the ban by the NGT impacted the project specifically. The argument that the delay
clause 14.3 on the grounds of orders of the National Green Tribunal (NGT) between 2015-18, non-payment of instalments by allottees, inclement weather conditions ... farmers, overall economic slow-down, orders of the National Green Tribunal (NGT) dated 11.01.2013, restraining all builders from utilising ground water for construction activities
stated to be force majeure reasons i.e. (i) National Green Tribunal (NGT)'s, order dated 11.01.2013 which restricted builders in Delhi NCR from ... water in tankers and the construction became slow and cost increased; (ii) NGT's order dated 17.09.2013 banned construction of the buildings within
villager agitations as well as legal impediments and because of orders of NGT, the delivery of project got rescheduled.
That clause ... majeure reasons, including inter alia, on account of certain orders passed by NGT, which would entitle the OP to extension of time without incurring
excessive rainfall and a restraint order of the National Green Tribunal (NGT) dated 28.10.2013 in MA No. 970 of 2013 pertaining to construction in Noida ... party waited for the Occupation Certificate which was delayed due to the NGT litigation. According to the opposite party, offer of possession was to have
