penalty imposed for delay in
completing the sample flat is stated to have been allowed without
recording reasons and ignoring the terms and conditions ... provision for extending the time for
completion of the sample flat nor the time was extended.
3.4 The grant of loss of on-site
also contended that no wood could have been
procured unless the sample flat was ready in terms of clause 5.3.1 at
OMP No.46/2001 ... Page 13 of 65
page 77 of the contract and the sample flat was completed in all respect
only in the first week of December
well for the
plot of land for the sample flat under ward no.M/E-
5012(2F)are not justified and deserve the notification ... nominal/lesser rate, rating the plot and the sample
flat as "Struck with Sterility" and therefore I inclined
to proposed to cancel
project land such as its site office, DDA office, sample flat for
the economically weaker sections etc. sometime in February/March 2008. It
was then
building and in the provision of other utility services.
A sample flat on site is normally made to enable prospective
purchasers to envisage the final
have been used for commercial purpose like corporate marketing office or sample flats on other plots.
19. The advertised group housing scheme promised a number ... stop commercial use and handover the site office and 3 sample flats blocks as space for social facilities and to collect all fines from
investments
to the extent of Rs.7.40 Crores, constructed a sample flat and
issued letters of allotment to 84 purchaser (which allotments
have subsequently
establish the site
infrastructure facilities including the construction of a sample flat for the
economically weaker sections, the Forest Department had raised objections
sufferer on account of petitioner's failure to complete even sample flats of Tower F
and Tower A in the project, had finally written
building and in the
provision of other utility services. A
sample flat on site is normally made
to enable prospective purchasers to
envisage the final
