Search Results Page

Search Results

1 - 4 of 4 (0.58 seconds)
Documents citing M/S Haliburton Offshore Services Inc. vs Vedanta Limited & Anr. on 29 May, 2020

Mytrah Vayu (Brahamputra) Private ... vs M/S. Solar Energy Corporation Of India ... on 18 March, 2024

Reliance was placed on the judgement of the Delhi High Court in M/s. Halliburton Offshore Services Inc. v. Vedanta Limited : OMP (I) (COMM) 88/2020 (Halliburton-1), to submit that the Delhi High Court had recognized that the restrictions imposed, pursuant to the outbreak of Covid-19, was a Force Majeure event, and created special equities in favour of the parties, and the Court had issued an ad interim order interdicting invoking or encashment of a bank guarantee issued in that case; reliance was also placed on the subsequent judgment dated 29.05.2020 passed in Halliburton - 2 to submitted that the Court had vacated the ad interim order, but had directed that the amount recovered be kept in a separate joint account.
Appellate Tribunal For Electricity Cites 48 - Cited by 0 - R Ranganathan - Full Document

H-Energy Private Limited vs Petroleum And Natural Gas Regulatory ... on 10 May, 2023

128. The Delhi High Court further held that the past non-performance of the Contractor cannot be condoned due to the COVID-19 lockdown in March 2020 in India; the Contractor was in breach since September 2019; opportunities were given to the Contractor to cure the same repeatedly; despite the same, the Contractor could not complete the Project; and the outbreak of a pandemic cannot be used as an excuse for non- performance of a contract for which the deadlines were much before the outbreak itself.
Appellate Tribunal For Electricity Cites 88 - Cited by 1 - Full Document

M/S Simbhaoli Power Private Limited vs Uttar Pradesh Electricity Regulatory ... on 16 March, 2026

inability not been able to recover the cost of supply of electricity in a reasonable manner by the Appellant, can be easily categorized as Force Majeure event which made it impracticable for the Appellant performed its obligations under the PPAs. He would submit that the provisions of the PPA must be given a holistic interpretation and need to be read in context of the scheme of Electricity Act to balance the interest of both the generator as well as the purchaser. He placed reliance upon the judgement of the Hon'ble Supreme Court in Satyabrata Ghose vs. Mugneeram Bangur & Co., (1953) 2 SCC 437, Energy Watchdog vs. CERC, (2017) 14 SCC 80 and the judgement of Delhi High Court in Halliburton Offshore Services vs. Vedanta Limited 2020 SCC online DEL 2068.
Appellate Tribunal For Electricity Cites 25 - Cited by 0 - Full Document

Wind Four Renergy Private Limited vs Central Electricity Regulatory ... on 11 January, 2022

17. The respondent SECI relies on the Order dated 29.05.2020 of the High Court of Delhi in O.M.P. (I) (COMM) No.88/2020 Halliburton Offshore Services Inc v. Vedanta Limited &Ors., as endorsed by the Hon'ble Supreme Court vide Judgment dated 08.10.2021 in Maharashtra State Electricity Distribution Company Limited v. Maharashtra Electricity Regulatory Commission and Others, 2021 SCC OnLine SC 913, the argument being that SCOD even in terms of the impugned order is much prior to imposition of lockdown due to Covid-19 on 25.03.2020, disruption due to pandemic being not available as an explanation.
Appellate Tribunal For Electricity Cites 4 - Cited by 1 - Full Document
1