Rule 4.1, the appointment of petitioner, though purely contractual, but was renewable on completion of contractual period, depending upon his performance and suitability, though ... respondents to treat the petitioner as purely contractual employee to discharge him on completion of contractual period of two years, without subjectively considering his right
competent authority.
SCC 3.5 Liquidated Damages for Delays in Completion Period
Damages for delay in completion under clause 32 of Form “A" shall ... liquidated damages shall be levied only in case of delay on contractual
completion period of that phase of sub-station.
SCC 8.1 The prices
requested the
respondent for release of the balance payment, extension of
contractual completion period, release of bank guarantee, return of
excess material, payment of additional
decided that the remaining length of the
pipeline would be completed through other contractors as and
when RoU became available.
11. After the aforesaid decision ... Park,
Dharampeth,Nagpur-
440010, Maharashtra
Sub: 8th Provisional time extension on Contractual
Completion Period for "Construction of ETP at NADA,
Additional Handling Facilities along
that the Petitioners
failed to make work fronts available within the contractual completion
period due to which the extension of about 3 months was granted ... they extended the contractual
period till 15/07/1999. Therefore, the Petitioners failed to prove all
work fronts within the contractual completion period and provided
said work was to be completed within a period of 12 months reckoned with effect from 18.4.81. You are requested to kindly refer ... reasons for delayed completion are not attributable to us. The completion of work has been extended beyond the contractual completion period that
Natrajan Ramkrishna vs Union Of India & Anr. on 7 February, 2025
Author: Yashwant Varma
Shrenik Baid vs Union Of India And Anr on 7 February, 2025
Author: Yashwant Varma
Snehal N Muzoomdar vs Union Of India & Anr. on 7 February, 2025
Author: Yashwant
M/S. Kerala Vision Limited vs Thrissur Corporation Electricity ... on 5 February, 2026
WP(C
