provide for extra cartage. According to him,
clause 3.16 of the Agreement stipulates that the contractor is
responsible for all the extra leads over ... respondent-
claimant cannot claim extra cartage @ Rs.30/- per cubic
meter on the ground of extra lead involved in bringing the
stone aggregates from Nooh
claimed an addi-
tional substantial sum in respect of lifts and extra leads
and certain other items together with the interest on the
amounts ... sought the orders of the Chief Engineer in writing for the
extra leads resulting from the conversion of lifts into
leads and that although
with which we are to deal with.
Claim No.1 - towards extra lead of 4 kms/6 kms-
stone and metal.
Claim ... High
Court.
PROCEEDING BEFORE THE ARBITRATOR
Claim No.I-Extra lead
7. The case of the appellant was that the
appellant was to quarry
borrow areas did not arise. The petitioner demanded payment for extra lead. It was not accepted. On this, the petitioner filed a claim under section ... lakhs (giving up claim of Rs. 15 lakhs) for extra lead of earth with interest and costs thereon.
3. The case of the petitioner
also read out. Non-availability of payment for extra leads and
lifts as per said clause, is also relied upon. Clause ... particularly Clause 4.2 dealing
with materials and prohibiting extra lead or claim for material
borrowed from area other than specified one, has been relied upon
parties that the
claimant is entitled to extra payment for the extra lead. The only
point at issue is whether Clause ... lead beyond initial lead of 3.0 km at the rate of
Rs. 198 per Cubic Mtr/Km) only if the said work of"extra
Difference due to [the] extra 1,21,80,944.00 76,81,461.00
cost incurred for procurement of
material involving extra lead on
account ... Difference due to [the] extra 81,17,355.65 67,86,655.00
cost incurred for procurement of
material involving extra lead on
account
they recommended the plaintiff to
dump the excavated material at extra lead charges. This
letter Ex.P.70 clearly shows that, due to the delay ... prove
additional works done with respect to watery situation and
extra lead charges
A) Ex.P12: This is a letter dated 15.12.1997 from
works with normal lead, since in
actual practice extra lead was involved, therefore,
CC No.182/01 CBI Vs S.K. RELAN & OTHERS Page ... recovered from
the two associates if they were paid for extra lead.
Pursuant to this decision accused B.B. Gupta
(deceased) addressed a letter dated
under Claim No. III for napaslabs or Claim No. VI for extra
lead of water or Claim No. IC for flattening of canal slopes ... claims respectively,
are: `Escalation on Napa Slabs'; `Payment of Extra Lead for
water; and, `Extra Expenditure incurred due to flattening of
canal slopes
