extension of time : No claim for compensation on account of delays or hindrances to the work from any cause whatever shall lie, except, as hereinafter ... contractor. The Executive Engineer shall assess the period of delay or hindrance caused by any written instructions issued by him, at twentyfive per cent
extension of time: No claim
for compensation on account of delays or
hindrances to the work from any cause
whatever shall lie, except, as hereinafter ... contractor. The Executive
Engineer shall assess the period of delay or
hindrance caused by any written instructions
issued by him, at twenty five per cent
extension of time :--No claims for compensation on account of delays or hindrances to the work from any cause whatever shall lie, except as hereinafter ... Contractor. The Executive Engineer shall assess the period of delay or hindrance caused by any written instructions issued by him, at twenty five per cent
make it the responsibility of the Contractor to make the site
hindrance free. He relies upon judgment of this Court in National
Highways Authority ... responsive to all these letters of the Contractor for the
removal of hindrances probably because it is his
contention, as stated in the SOD that
issued
by the petitioner wherein it was recorded that there was no hindrance
in the execution of the work and whatever hindrances were pointed ... reading the letters it was pointed out that there was no
hindrance in the execution of the work and whatever
hindrances were pointed
land both for working and dumping for
continuity of work without any hindrance. Again on
21.05.2018, petitioner no.1 intimated the opposite party-
MCL that ... both for working and
11
dumping for continuity of work without any hindrance.
Thereafter, correspondences went on between petitioner
no.1 and opposite party
would not be completed on time owning to various bottlenecks viz, hindrances at the site of construction, variation in earthwork, resistance by villagers ... extensions granted to the petitioner as well as the length of the hindrances at the site of construction has been provided by the petitioner
returned categorical findings by placing reliance on the
records i.e. hindrance register maintained and signed by the petitioner
itself. Reliance is placed on Delhi ... Builders.8
31. It is also submitted that the contents of the hindrance register were
neither challenged by the petitioner in the present petition
public and residents of the colony had put up several hindrances in the
form of encroachments, as a result of which the resources ... April 2002, the respondent again wrote to MCD stating
that the hindrance free site had yet to be made available to it. It was
pointed
Respondent also relied upon its Letter
dated 10.10.2014 to state that the hindrances mentioned in the Letter were
not considered by the Petitioner. Reliance ... justified delay, and issue of drawings
versus progress at site reflected continued hindrance on account of rains,
issue of drawings, revision in drawings, change
