work executed at site. The responsibility as per work order
of procuring bitumen from authorized source was on the contractor
only and the appellant being ... said argument as the work orders stipulated that original receipt
of bitumen procured from an authorized government refinery was to
be submitted to MCD which
percentage of factors bitumen, cement and steel (X,Y,Z)
was the actual percentage of cost of procurement of these articles in the said
month ... work.
v. Adjustment for Bitumen Component
Price adjustment for increase or decrease in the cost of
bitumen procured by the Contractor shall be paid
different techniques of blending. The
storage stability of modified bitumen is very important. The
modified bitumen shall preferably be blended at or near ... blending CRMB -60 Grade, at site, with the bitumen
procured. This proposal of the respondent envisaged, having a separate
independent entity collaborate with one, Samy
done and also record the stone aggregate, stacks as well as the
bitumen on 14.05.1999 at 10.30AM. Otherwise it seems that the
department ... bitumen and arrangement for sending
the sample were very genuine under the agreement so as to ascertain the
source of such bitumen procured
cross-examination, explained that the details of work done
including procurement of Bitumen, rubber and stone, laying of road and also
measurement of road ... explained that MB have the details
of the work done including procurement of Bitumen, rubber and stone,
laying of road and measurement of the work
changes in government policy and sharp escalation in the price of bitumen, the petitioner invoked Clause 10F of the General Conditions of Contract and sought ... increased/'decontrolled' prices that it had to pay for procuring bitumen. As the respondent disputed the coverage of the claim by the said
MKEL had disputed the extent of recovery as bulk
of bitumen was procured after March, 2016 when the basic strip was
handed over to MKEL ... calculated on the basis of price as applicable when
bitumen was procured, which was after handing over of site on
26.03.2016. AAI had calculated
plea of the appellant that there
was delay in procurement of bitumen for which the respondent was
responsible and should have granted extension of time
road rollers and bitumen vide his letter dated 19.9.1984. She has contended that at that relevant time, the bitumen was cheaper in open market then ... Chief Engineer of the respondent that he was prepared to supply bitumen by procuring it from outside sources at a cheaper rate and for that
Bitumen was
always available on site, the HMPs capacity was only 240 tonnes and for
the remaining work, the Bitumen could not be procured owing ... source
approval or JMF approval of the material to be procured, the Bitumen
could in no way be brought to the site
