progress of work.
iv) On 23rd August, 2004, another letter was issued by the
petitioner stating that the progress of work was very slow ... work was slow and that the structural work
could not be completed by the stipulated 18 months period for
completion of structural work
work order was
issued on 10.07.2006 and the plaintiff duly started the work within 15 days
therefrom. During the progress of the work, the field ... alleged slowness of the work.
The delay and the slowness were caused by the department. While the work was
in progress, the plaintiff received
works in the absence of
such an analysis, AT is not in a position to appreciate the
charts submitted by Respondent showing the progress ... admitted delays and disruptions of
Respondent/Engineer would undoubtedly cause slow
progress of work in available stretches, for which
Claimant cannot be faulted or responsible
work.
As per the contract, the work was to commence on 28-10-2010 and
completed by 5-4-2012. When the work ... indicating its
intention to unilaterally rescind the contract due to slow progress of
work and to entrust the execution of the balance works
labour. However,
according to it, the Respondent did not facilitate the progress of work. A
reference has been made to the letter dated ... Work Order. The letter listed out the grievances including
the slow progress of work which had pushed the delivery of the said towers
matter of fact, petitioner was warned
about the slow progress of the work
through letter dated 18.02.2015
(Annexure-R2) and petitioner vide e-
mail dated ... letters written by the respondent to the petitioner about the slow
progress of the work they are general in nature and they do not
throw
faulted for non-provision of the work fronts. She fairly
submitted that the works as originally contemplated could not be executed
because TTZ Commissioner ... Contract.
According to GGL, ARIO's work progress was slow. This is not disputed
by ARIO. But, it is contended that the works suffered
days of the week and the work thus could not be carried out in
full swing as the work involved renovation of rooms and halls ... slow progress
of the work; (v) after much persuasion, fourth site was handed over but the
progress of the work still remained slow
evaluation on the
ground of the endorsement in the Work Load Return as „No, Slow
Progress‟.
5. Learned counsel relies on the decision of „Prakash ... Commander Works
Engineer (AF), the operation of the endorsement „No, Slow Progress‟ in
the Work Load Return shall remain suspended. The respondent shall also
remove
reason of the petitioner having not completed
the work, the progress of work being extremely slow, and the
Patna High Court CWJC ... rescinding the contract would be made in view of the slow
progress of work. The notice only required the petitioner to
expedite the completion
