appellant-company in his various meetings had admitted
about the slow progress of the work due to cash flow problem of the firm as well ... work on their part and reaffirmed their commitment to complete the
work by 31.10.2017. In the said meeting, he mentioned that the slow progress
work after stipulated period
of contract till the completion of work is Rs.599.75 Lakhs, that
the average monthly shortfall of progress during contract ... 5178/2005
that penalty was imposed upon the Plaintiff due to slow work
progress, that the Plaintiff having obtained extension of time for
executing additional
work within the stipulated time of completion due
to slow progress of work and as such, the extensions were
granted under clause ... respondent cannot be blamed for the slow
progress of the work. The delay in the work was caused due to
change in designs
availability of site for footpath (8) slow progress of work from
Chitra Vihar to PSK and (9) execution of extra work beyond the
contract ... availability of site for footpath,
(8) slow progress of work from Chitra Vihar to PSK, and
(9) execution of extra work beyond the contract
Consequentially, the Project Director, DRDA
expressed her displeasure on the slow progress of work.
Though the place of posting of the petitioner was fixed
letter dated 20.03.2020 issued by
MSRDC alleging that the progress of the works was slow and the same
was being done in a haphazard ... 2020 Page 4 of 10
contract on account of slow progress of the work alleging that the
respondent had not shown any will to complete
Respondent could not provide inputs for
preparation of drawings for execution of work. Be that as it may, the
Petitioner could not conclusively prove ... Claimant had to be repeatedly advised about
the slow progress of work both through letters and meetings. The Claimant
had also not put in matching
avail. Finally,
being fed up with the slow progress of work,
inasmuch as the petitioner company could
complete only 64% of the work within ... deliberately
defaulted in completing the work in question and
its pace of work had always been slow. It has also
been submitted that the petitioner
required to complete the
CCTV cameras installation work within four months from the date of the
work order and the defect liability period/warranty ... from the date of actual completion.
However, the petitioner showed slow progress of work and the quality of
CCTV cameras installed by it was also
execute the work as per the work programme, failing which
appropriate action would be taken. In fact the progress of the
work was reviewed ... started the work after a great delay
and then also its progress regarding completion of the work was
found to be very slow on account
