suspension
of work for different spells, between October, 1989 to
December, 1990. If so how?
(ii) Whether the claimants are entitled to bonus ... following grounds:
(a) That the claim on account of suspension of work from October, 1989 to
August, 1990 and from September, 1990 to December
flooding at the work site and the subsequent suspension of work. It
conveyed by various letters during September 1992 that most of the
machinery ... works for restoration of the works lost and damaged
had been taken up. Repairs of the plant and machinery were required
for restoration of works
closing of river gap, the work was severely delayed as
even suspension of work took place, over and above the
frequent disruption in the power ... piece and that caused delay in the work as
even suspension of the work for the same had to be made.
The barrel required
opposite party No.1 placed the petitioner under
suspension vide Order No.18076-- WORKS-CON-
CASES-0051-2022, dated 14.12.2022 (Annexure-9).
2.4. Filing petition ... initiated within 30 days from the date of suspension, it
is only on 07.12.2023 that the Works Department has
appointed Inquiring Officer even while
further agreement
extending the work beyond 30.08.2018. Question of suspension of work
will arise only if the contract subsists. Assuming that the contract subsists,
variations ... delays and suspension of work was governed by Clause 6 of
Exhibit C.3 PMC Agreement dated 27.04.2016. Clause 6 of PMC
Agreement dated
stop fabrication and erection of structural steel work and
the suspension of work at structural steel activities were not lifted by
26
the NBCC till ... completion of the contract was set at large and the suspension
of work at the steel structural zone was subsisting, the NBCC has
terminated
stop fabrication and erection of structural steel work and
the suspension of work at structural steel activities were not lifted by
26
the NBCC till ... completion of the contract was set at large and the suspension
of work at the steel structural zone was subsisting, the NBCC has
terminated
work site and work site was handed over on 24-4-2012.
Document available at page 22 shows that the contractor started the
preliminary work ... ground improvement work saying that the rate relating to
work for ground improvement could have been finalised keeping the work
in progress. By the documents
idleness of the petitioner‟s establishment
which happened due to wrongful suspension work from his part.
[5] The respondents rescinded the agreement on 10.01.2012.
Thereafter ... also submitted that the work suffered inordinate delay due to
suspension of the work by the claimant from time to time and due
to fault
when there was suspension of work for
which the writ petitioner is not entitled to gratuity for
those years. After discussing the law prevailing prior ... petitioner was not entitled to gratuity when
the factory was under suspension of work.
The appellate authority has also considered the
judgement reported
