contained in the aforesaid PPA, terminated the PPA vide its letter
dated 11.01.2011. The PPA was terminated after the Order on the Petition filed ... invoked the Arbitration Clause in the terminated
PPA and commenced arbitration. The said arbitration proceedings are pending.
N. This Tribunal passed its final order
either extend the time for fulfilment of conditions precedent or
to terminate the PPA. Further, the State Commission has also held
that the re-fixed ... choose to terminate the agreement as
per the provisions of Article 16."
Therefore, the Respondent may consider to terminate the
PPA under Article
upon the
first Respondent to cure the Construction Defaults and to terminate the
PPA. Taking all relevant facts into consideration and also judgment ... upon the first Respondent to cure the
construction defaults and to terminate the PPA. Therefore, he submitted
that, analysis of the clause of the PPA
granted
by the GUVNL even though the GUVNL was entitled to
terminate the PPA due to delay beyond one year from SCOD?
B. Taxus
right in dealing with the aspect that Lanco
was entitled to terminate the PPA and enforce compulsory buyout of the plant
by the Appellant when
KSEB Ltd for fulfillment of
the RPO of KSEB Ltd as per PPA dated
04.07.2006. Only the Renewable Energy
Projects which commenced operation after ... Page 24 of 39
A. No. 157 of 2016
projects cannot terminate such PPA for availing
the benefit of REC. The SHP of the petitioner
CSPTCL
had terminated the interim arrangement for supply of power
from July 2011 to March 2012. BALCO accepted such
terminations without demur or any claim ... authentication of the same.
d) Appellant has never disputed or terminated the PPA concluded
though correspondence. The Appellant has been availing
(procuring) power without execution
Gujarat Urja Vikas Nigam Limited & Ors vs Renew Wind Energy (Rajkot) Private ... on 6
Government Order but on the basis that the PPA itself
stood terminated with effect from 3rd May, 2010. The absence of any
materials
wise.
c) Withdrawal of Deemed Export Benefit in relation to the
MSEDCL PPA:
i. The Central Commission has erred in holding that the
withdrawal ... advance authorization as
opposed to deemed export duty drawback and exemption
from terminal excise duty. On 21.03.2012 the Foreign Trade
Policy (FTP) was amended
