with both.
50. Section 138 relates to the interference with meters or works of licensee.
As per this Section, whoever unauthorisedly or maliciously tampers with ... with both.
51. Section 139 deals with negligently breaking or damaging works.
According to this Section, whoever negligently breaks, injures, throws down or
Page
left bank
protection works of dam due to cloud burst, damage to civil
works on account of cavity formation in crown and left wall ... rectification of HRT while Rs.1387
lacs for rectification of damaged works in dam, pressure
shaft, surge shaft and power house were disallowed.
Page
Taxus Infrastructure & Power Projects ... vs Gujarat Electricity Regulatory ... on 4 July, 2018
A.NO
liquidated damages recovered by the respondent, in
excess of the liquidated damage worked out for this period, shall be
____________________________________________________________________
Review Petition
suddenly there
was a flash flood. This caused damage to the barrage
works and resulted in suspension of the generation of
energy from ... amounting to Rs.67.88 Crores towards the restoration
of the damaged works caused by the flash flood. As
per the PPA, the event
about this Force Majeure event
resulting in extensive damage to equipment and civil
works. On 1.2.2006 the Appellant Electricity Board
directed its Chief Engineer (Projects ... that the estimated cost of the
replacement of damaged equipment and restoration of
damaged civil works would be about Rs.21 Crores
down from June, 2013 to
March, 2014. Further, the restoration work for the damage caused
to the said cloudburst is not fully complete ... shut down from June, 2013
to March, 2014. The restoration work for the damage caused
due to the said cloudburst is not fully complete
Order of invocation would cause irreversible damage to
Essar Power. It will not have the requisite working
capital for generating and supplying power. The Force
compensation or rent to the persons affected by
works under this Section;
(f) the repairs and works to be carried out when
emergency exists ... inconvenience as possible in
carrying out the works and to make compensation for
the said damage or inconvenience.
Page 23 of 78
Judgment in Appeal
Punjab State Power Corporation Ltd vs Everest Power Private Limited & Ors. Jmc ... on 11
