delay and there was also delay in setting
up of casting lines, erection of gantry, cranes, casting of mock
up segments and this delay ... have issued the GFC drawings
and could not have contended that the GFC drawings were
not issued due to the delay in pile load test
defines them
as drawings submitted with the tender. Clause No. 5.1
defines contract drawings as the drawings that had to be
issued along with ... drawings. All most the defendant
relies more than 300 drawings and there is a detail
discussion about furnishing of drawings and delay in
completion
delay on their side
in clearing the site for executing the work and there is no
delay in payment. Plaintiff himself caused inordinate
delay ... Judgment .doc
(1) delay in supply of approved working drawings.
(2) delay in shifting of highÂtension electric line,
telephone line and Municipal water supply
have
also denied the plaint allegations that the delayed interim
payments, delayed supply of working drawings, abnormal
delay in completing the water supply, sanitary ... contract
work above the plinth beam was delayed due to delay in
supplying of working drawings by the defendants.
Plaintiff has further alleged that
responsible for delay until 31st December,
2012 has relied upon mere ipse-dixit of CW1 on delay in supplying
drawings and contradicts the express provisions ... delay was
because of the Petitioner and not the Respondent. He has submitted
that the Respondent has alleged that the delay was in issuing
drawings
responsible for delay until 31st December,
2012 has relied upon mere ipse-dixit of CW1 on delay in supplying
drawings and contradicts the express provisions ... delay was
because of the Petitioner and not the Respondent. He has submitted
that the Respondent has alleged that the delay was in issuing
drawings
attributed for delay in execution of work,
the Tribunal records as under:
"22.2. Regarding the delay in supply o the drawings and designs, neither ... Therefore, the Tribunal findings on delay in handing over the site
and delay in handing over designs and drawings is not sustainable.
We uphold
work. With regard to such
subsequent delays, he submitted that the Petitioner admittedly delayed
the approval of drawings by about three months. As a result ... only about 128 days of
delay(68 days on account of delay in approval of detailed designs and
drawings and a further two months
delay is attributable to the defendant. It is stated that
defendant has satisfied the tribunal that the delay is in
issuance of land, GFC drawings ... that the defendant has
clearly estsablished that delay in handing over of land and
issuance of GFC drawings by the plaintiff affected the
progress
Supreme Court and not considered delay in handing over the
site, delay in preparing drawing for the execution of work and
failed to analyze ... tribunal has not considered
the delay in handing over the land, delay in preparing the
drawings for the execution of the works in time manner
